(a) General contractor apos s work ECU 3.9 6.2 million

OIOS found that the contractor had not complied with the terms and conditions of the contract pertaining to general obligations of the contractor and claims .

1. Contractor

2. General agreement

B. General agreement

34. General agreement . 13

OIOS is recommending that strong action be taken against the contractor in accordance with the general obligations of the contractor clauses of the contract until the project is finally completed (recommendations 2 and 4).

The security strengthening projects team, in agreement with the contractor, has engaged the construction management firm to perform a detailed evaluation and show the correct situation.

57. Consequently, the settlement agreement included a deduction of ECU 2 million for liquidated damages caused by delays attributable solely to the contractor. III. AUDITS CONDUCTED

Criminal charges against contractor officials

Big contractor now. Mr. Reardon?

(c) Contractor apos s financial claim

11. However, the contractor encountered another delay.

Chairmanship of quarterly meetings in Rome and discussions with contractor on claims February Finalization of discussions regarding settlement withdrawal of force majeure claim by contractor. Meetings with ECA representatives, consultants and contractor apos s senior management

GATT General Agreement on Tariffs and Trade

37. An individual contractor will be engaged under a contract for individual contractor entered into by the Organization directly with the individual.

10. As recommended by the Board of Auditors and requested by the General Assembly, the contract with the main contractor was revised.

Section B. General terms of the project agreement

Therefore, as from that date, the contractor is in default of the contract and the capital master plan office and the Procurement Service should enforce the default clause of the contract in its entirety, particularly in respect to general obligations of the contractor and claims .

2. Tasks expected to be completed by the contractor

53. The final settlement agreement included ECU 2.2 million for these financial claims, which took into consideration the recommendation made by the quantity surveyor for services provided by the contractor that were deemed reasonable and for which the United Nations received value, as well as administrative costs from delays entitling the contractor to further extension of time.

quot Mindful of the importance of reaching general agreement,

General agreement 1. The Commission, its subcommissions and subsidiary bodies shall make their best endeavours to ensure that their work is accomplished by general agreement.

The agreement reached brings basic telecommunications into the framework of the General Agreement on Trade in Services (GATS).

The bond is the United Nations lien against contractor performance.

As contractor for the payload INMARSAT 3 and Koreasat (Korea)

An individual contractor need not work on United Nations premises.

The claimant (main contractor) appealed against the decision of a lower court, which had referred various disputes between the claimant and the respondent (sub contractor) to arbitration.

The proposed conversion of 395 interpreter translator individual contractor positions to national General Service posts could help to reduce the high vacancy rates in the Mission.

August Meetings with the consultants and the contractor to review force majeure claims, programming problems and construction progress November Meetings with the architects engineers and the contractor on

DR No. In fact I told the contractor to go ahead.

IS3.68 The new contractor at Headquarters started operations in April 2003.

Since 1994, additional contractor costs have arisen in the following areas

The program was only exposed when former NSA contractor Edward Snowden

14.1 The Contractor shall permit the Authority to send its inspectors on board vessels and installations used by the Contractor to carry out activities in the exploration area to

1994 General Agreement on Trade in Services Organization Multilateral Binding Adopted

20. The Secretary General is basically in agreement with this recommendation.

10. Also requests the Secretary General to determine contractor responsibilities in the changes in the Integrated Management Information System in order to limit unnecessary payments by the Administration

These duties have been performed by an independent contractor since June 2003.

France and Germany will make the spectrometer together, with CNES as contractor

No further work is foreseen, and the contractor has been notified accordingly.

We had a meeting that evening with his contractor of choice, and the contractor showed up with the drawings of the platform about half the size that we had drawn it.

(b) For the main contractor, the contract was signed six days after a newspaper reported that the contractor had pleaded guilty to making short payments to workers and consequently had made restitution and paid fines amounting to millions of dollars, and that the contractor would be barred from future Government contracts.

The authors draw attention to paragraph 19, eighth sentence, of the OECD Commentary which reads If an enterprise (general contractor) which has undertaken the performance of a comprehensive projects subcontracts parts of such a project to other enterprises (subcontractors), the period spent by a subcontractor working on the building site must be considered as being time spent by the general contractor on the building project (emphasis added).

There is no general universal agreement on the definition of indigenous peoples.